Effective Date: June 19, 2026
Last Updated: June 19, 2026

Welcome to Marenzo Construction Group (“we,” “us,” or “our”). Founded in 2010 by Gino Carini, Marenzo Construction Group is a Milwaukee, Wisconsin-based general contractor serving clients throughout Milwaukee and Southeastern Wisconsin. We specialize in the construction of commercial, retail, industrial, office, and community buildings, offering services ranging from planning and program development to design coordination, construction documents, and complete turnkey construction projects.

By engaging in our services, signing a construction contract or proposal, requesting a quote, visiting our website, or entering into any service agreement with us, you (“Client,” “you,” or “your”) agree to be bound by the following Terms of Service (“Terms”). These Terms apply to all project engagements, unless a separately executed written contract expressly supersedes them. Please read these Terms carefully before completing any engagement.

1. Scope of Services

Marenzo Construction Group provides general contracting, construction management, and pre-construction services for commercial, retail, industrial, office, and community facility projects throughout Milwaukee and Southeastern Wisconsin, including but not limited to:

New commercial, retail, industrial, and office construction
Retail storefronts, restaurant buildouts, and multi-location retail projects
Warehouse, manufacturing facility, distribution center, and industrial expansion construction
Office build-outs, interior fit-outs, tenant improvements, and office renovations
Community centers and large-scale commercial developments
Planning, program development, and pre-construction consulting
Design coordination and construction document management
Complete turnkey construction project delivery
Project management, scheduling, and budget oversight

All services are performed in accordance with the applicable executed contract, proposal, statement of work, or purchase order (“Project Agreement”), which is incorporated into and governed by these Terms. Marenzo Construction Group works closely with owners, architects, and subcontractors to deliver projects that are functional, durable, and built to meet the unique needs of each client.

2. Estimates, Proposals & Contracts

All written proposals and estimates are valid for thirty (30) days from the date of issuance unless otherwise stated in writing. Proposals do not constitute binding commitments until a formal Project Agreement is executed in writing by both parties.

No work will commence until a signed Project Agreement and any required deposit or retainer have been received by Marenzo Construction Group. Verbal agreements, email approvals, or other informal communications do not constitute an executed contract.

Scope changes, additions, or modifications to agreed work must be documented in a written change order signed by both parties prior to commencement of the changed scope. Marenzo Construction Group reserves the right to adjust the project schedule and total contract price to reflect approved change orders.

3. Payment Terms

Payment terms are established in the applicable Project Agreement. Unless otherwise agreed in writing, the following default terms apply:

A deposit or mobilization payment, as specified in the Project Agreement, is due prior to project commencement.
Progress payments are due within fifteen (15) days of invoice date, in accordance with the payment schedule set forth in the Project Agreement.
Final payment is due upon substantial completion of the project, as defined in the Project Agreement.

Past-due balances will accrue interest at the rate of one and one-half percent (1.5%) per month (18% per annum), or the maximum rate permitted by applicable Wisconsin law, whichever is less. Marenzo Construction Group reserves the right to suspend work on any project where payment is more than fifteen (15) days past due, without liability for resulting delays or cost increases.

Client is responsible for all applicable taxes, permit fees, utility connection fees, and other governmental charges associated with the project, unless expressly included in the contract price.

4. Change Orders & Scope Modifications

Construction projects are subject to unforeseen site conditions, Client-requested changes, and evolving regulatory requirements that may affect project scope, schedule, and cost. Any change to the contracted scope of work—including additions, deletions, or substitutions—must be documented in a written change order executed by both parties.

Marenzo Construction Group is not obligated to perform work outside the agreed scope without an executed change order. If Client directs or requests work outside the contracted scope without executing a change order, Client acknowledges liability for the reasonable cost of such work, which will be invoiced at Marenzo Construction Group’s prevailing rates.

Marenzo Construction Group will provide written notice of any condition discovered during construction that is reasonably likely to affect cost or schedule, including unforeseen subsurface conditions, hazardous materials, code compliance issues, or structural deficiencies not identified in pre-construction investigations.

5. Project Schedule & Delays

Marenzo Construction Group will use commercially reasonable efforts to complete the project within the schedule established in the Project Agreement. However, project timelines are estimates and are subject to change due to factors including:

Client-requested scope changes or delayed Client approvals, selections, and decisions
Delays in receipt of materials, equipment, or subcontractor services
Adverse weather conditions, acts of God, or other force majeure events
Labor disputes, strikes, or work stoppages
Regulatory delays, permit processing times, municipal inspection scheduling, or hold-ups from the City of Milwaukee or Southeastern Wisconsin jurisdictions
Discovery of unforeseen site conditions, including subsurface conditions or concealed structural deficiencies

Marenzo Construction Group will provide written notice of anticipated delays and, where practicable, an updated project schedule. Delays caused by factors outside Marenzo Construction Group’s reasonable control will entitle Marenzo Construction Group to a corresponding extension of the project schedule without additional cost to Client.

6. Client Responsibilities

To enable Marenzo Construction Group to perform its work efficiently and on schedule, Client agrees to:

Provide Marenzo Construction Group with timely access to the project site, including keys, access codes, property manager contacts, or escort arrangements as required.
Provide accurate and complete information regarding the project site, including known subsurface conditions, utility locations, existing structural conditions, hazardous materials, and any applicable lease or landlord restrictions.
Obtain and maintain all necessary permits, approvals, and utility consents that are the responsibility of the property owner under applicable law, unless expressly delegated to Marenzo Construction Group in the Project Agreement.
For tenant improvement and leased-space projects: provide Marenzo Construction Group with a copy of the applicable lease agreement and any landlord work-letter, approval requirements, or building standard specifications prior to commencement of construction.
Make timely decisions, selections, and approvals as required to avoid delays to the project schedule.
Designate an authorized representative with decision-making authority on behalf of Client throughout the project.
Secure and maintain adequate property insurance covering the project premises, existing structures, and Client’s personal property throughout the duration of the project.

Marenzo Construction Group is not liable for delays, cost increases, or project disruptions resulting from Client’s failure to fulfill the above responsibilities.

7. Tenant Improvement & Leased-Space Projects

For projects involving construction or renovation within a leased premises—including retail buildouts, office fit-outs, and tenant improvements—the following additional terms apply:

Client is solely responsible for obtaining landlord approval of construction plans, specifications, and contractors prior to commencement of any work, unless Marenzo Construction Group has been expressly engaged in writing to obtain such approvals on Client’s behalf.
Client is responsible for ensuring that the Project Agreement’s scope and specifications conform to any landlord-imposed building standards, base building conditions, and lease requirements. Marenzo Construction Group is not liable for construction that cannot be completed due to lease restrictions, building system conflicts, or landlord disapproval of which Marenzo Construction Group was not notified in writing prior to contracting.
Restoration obligations imposed by the lease at the end of the tenancy are the sole responsibility of Client unless expressly addressed in the Project Agreement.
Any delays attributable to landlord approval processes, building access restrictions, or coordination with base building contractors are outside Marenzo Construction Group’s control and will be addressed by change order as applicable.

8. Permits & Regulatory Compliance

Marenzo Construction Group will obtain building permits and other construction-related permits that are customarily the responsibility of the general contractor under Wisconsin law, as specified in the Project Agreement. Permit costs are either included in the contract price or itemized as a reimbursable expense, as set forth in the Project Agreement.

All work performed by Marenzo Construction Group will comply with applicable Wisconsin Uniform Dwelling Code, Wisconsin Commercial Building Code, City of Milwaukee building codes and ordinances, applicable Southeastern Wisconsin municipal requirements, OSHA safety regulations, and other federal, state, and local standards in effect at the time of construction.

Client is solely responsible for ensuring that the intended use and occupancy of the completed project complies with applicable zoning, land-use, licensing, ADA accessibility, fire safety, and operational regulations governing Client’s specific business operations. Marenzo Construction Group does not provide legal, zoning, or regulatory compliance advice and is not responsible for Client’s operational licensing or occupancy approvals beyond the construction permit process.

9. Architects, Design Professionals & Third-Party Coordination

Marenzo Construction Group regularly works alongside architects and design professionals engaged by Client. Where Client has retained an architect or design professional (“Design Professional”) separately from Marenzo Construction Group:

Client is responsible for the completeness, accuracy, and code compliance of design documents, drawings, and specifications prepared by Client’s Design Professional. Marenzo Construction Group is entitled to rely on such documents and is not responsible for errors, omissions, or code violations contained therein.
Any additional costs or delays resulting from design errors, omissions, incomplete documents, or design changes initiated by Client or Client’s Design Professional after construction has commenced will be addressed by change order at Client’s expense.
Coordination between Marenzo Construction Group and Client’s Design Professional for shop drawing reviews, RFI responses, and construction administration is the responsibility of Client unless a formal construction administration role has been agreed upon in writing.

Where Marenzo Construction Group provides pre-construction consulting, program development, or design coordination services as part of a turnkey or design-assist delivery model, the specific scope of such services and associated responsibilities will be set forth in the Project Agreement.

10. Subcontractors

Marenzo Construction Group employs qualified, licensed subcontractors to perform specialized scopes of work. Marenzo Construction Group is responsible to Client for work performed by its selected subcontractors as if performed directly by Marenzo Construction Group, except as otherwise provided in these Terms.

Where Client has requested the engagement of a specific subcontractor, vendor, or supplier not selected by Marenzo Construction Group (“Client-Designated Contractor”), Marenzo Construction Group’s responsibility for that party’s work, schedule performance, and workmanship is limited. Marenzo Construction Group will coordinate with Client-Designated Contractors in good faith but does not warrant or guarantee the work of any party chosen by Client.

Client may not directly engage separate contractors to perform work on the same project site during the term of the Project Agreement without prior written consent from Marenzo Construction Group. Unauthorized interference with the project site or workforce may result in schedule delays, additional costs, safety concerns, and suspension of work.

11. Warranties

11.1 Construction Warranty

Marenzo Construction Group warrants that all work performed under a Project Agreement will be completed in a workmanlike manner, consistent with applicable industry standards, and free from defects in materials and workmanship for a period of one (1) year from the date of substantial completion (“Warranty Period”), unless a longer period is required by applicable Wisconsin law.

This warranty does not cover:

Normal wear and tear, settling, shrinkage, or surface weathering consistent with industry standards
Damage resulting from Client’s misuse, modification, neglect, or failure to perform routine maintenance
Damage caused by third parties not engaged by Marenzo Construction Group
Damage resulting from force majeure events, including floods, extreme weather events, or other natural disasters
Defects arising from design documents, specifications, or materials provided, selected, or specified by Client or Client’s Design Professional
Conditions attributable to pre-existing deficiencies in the building structure, base building systems, or site conditions not disclosed to Marenzo Construction Group prior to contracting

11.2 Manufacturer and Supplier Warranties

Materials, equipment, and fixtures installed by Marenzo Construction Group may carry separate manufacturer or supplier warranties. Marenzo Construction Group will assign the benefit of any such warranties to Client at project completion to the extent they are assignable.

11.3 Disclaimer

EXCEPT AS EXPRESSLY SET FORTH IN SECTION 11.1, MARENZO CONSTRUCTION GROUP DISCLAIMS ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, INCLUDING ANY IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, OR NON-INFRINGEMENT, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW.

12. Hazardous Materials

Unless expressly included in the Project Agreement, Marenzo Construction Group’s scope of work does not include the identification, testing, abatement, removal, handling, transport, or disposal of hazardous materials, including but not limited to asbestos, lead-based paint, mold, contaminated soil, PCBs, or other regulated substances.

If hazardous materials are discovered during construction, Marenzo Construction Group will promptly notify Client and suspend affected work pending Client’s engagement of licensed hazardous materials professionals. Client bears full responsibility and cost for remediation not within Marenzo Construction Group’s agreed scope. Any resulting project delays or additional costs will be addressed by change order.

Client warrants that, to the best of Client’s knowledge, Client has disclosed all known or reasonably suspected hazardous conditions at the project site prior to execution of the Project Agreement.

13. Intellectual Property

All pre-existing intellectual property owned by Marenzo Construction Group, including proprietary construction methods, estimating systems, project management processes, and know-how, remains the exclusive property of Marenzo Construction Group.

Project-specific construction documents, coordination drawings, and plans prepared by Marenzo Construction Group remain the property of Marenzo Construction Group unless expressly transferred in a signed written agreement. Upon receipt of full payment, Client is granted a non-exclusive, non-transferable license to use such documents solely for the specific project for which they were prepared.

Drawings, specifications, and design documents prepared by Client’s architect or design professional remain the property of their respective authors. Client warrants that it has the authority to provide such documents to Marenzo Construction Group and that Marenzo Construction Group’s use of such documents does not infringe any third-party rights.

14. Insurance

Marenzo Construction Group maintains the following insurance coverages throughout active project engagements:

Commercial General Liability Insurance
Workers’ Compensation and Employer’s Liability Insurance, as required by Wisconsin law
Commercial Automobile Liability Insurance
Builder’s Risk Insurance, where applicable to the project scope

Certificates of insurance are available upon written request. Specific additional insured, waiver of subrogation, or coverage limit requirements must be identified by Client in writing prior to execution of the Project Agreement.

Client is responsible for maintaining property insurance covering Client’s existing structures, contents, tenant improvements, and personal property at the project premises throughout the duration of the project. For leased-space projects, Client is responsible for confirming that its lease and insurance coverage adequately address construction activities. Marenzo Construction Group is not liable for damage to Client’s uninsured or underinsured property absent Marenzo Construction Group’s proven negligence.

15. Indemnification

Client agrees to indemnify, defend, and hold harmless Marenzo Construction Group, its owners, officers, employees, agents, and subcontractors from and against any and all claims, losses, damages, liabilities, and reasonable attorneys’ fees arising out of or related to:

Client’s breach of any obligation under these Terms or the applicable Project Agreement
Client’s misrepresentation of site conditions or failure to disclose known hazardous materials, structural deficiencies, or lease restrictions prior to contracting
Client’s engagement of separate contractors or third parties on the project site without prior written consent from Marenzo Construction Group
Client’s failure to comply with applicable laws, zoning requirements, landlord obligations, or occupancy and licensing requirements
Errors, omissions, or code violations in design documents, specifications, or materials provided by Client or Client’s Design Professional

Marenzo Construction Group agrees to indemnify Client from claims arising directly from Marenzo Construction Group’s proven gross negligence or willful misconduct, to the extent permitted by applicable Wisconsin law.

This indemnification obligation survives the expiration or termination of any Project Agreement.

16. Limitation of Liability

TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, MARENZO CONSTRUCTION GROUP’S TOTAL AGGREGATE LIABILITY TO CLIENT FOR ANY CLAIM ARISING OUT OF OR RELATED TO THESE TERMS OR ANY PROJECT AGREEMENT SHALL NOT EXCEED THE TOTAL CONTRACT PRICE PAID BY CLIENT TO MARENZO CONSTRUCTION GROUP UNDER THE SPECIFIC PROJECT AGREEMENT GIVING RISE TO THE CLAIM.

IN NO EVENT SHALL MARENZO CONSTRUCTION GROUP BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, PUNITIVE, OR EXEMPLARY DAMAGES, INCLUDING LOSS OF REVENUE, LOSS OF BUSINESS, LOST PROFITS, LOSS OF ANTICIPATED SAVINGS, BUSINESS INTERRUPTION, LOSS OF GOODWILL, OR LOSS OF DATA, WHETHER ARISING IN CONTRACT, TORT (INCLUDING NEGLIGENCE), STATUTE, OR OTHERWISE, EVEN IF MARENZO CONSTRUCTION GROUP HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

Nothing in these Terms excludes or limits liability for death or personal injury caused by Marenzo Construction Group’s negligence, for fraud or fraudulent misrepresentation, or for any liability that cannot be excluded or limited under applicable Wisconsin or federal law.

17. Cancellation & Termination

17.1 Termination by Client for Convenience

Client may terminate a Project Agreement for convenience upon thirty (30) days’ prior written notice to Marenzo Construction Group. Upon termination for convenience, Client shall pay Marenzo Construction Group for:

All work completed and in progress through the termination date, at the proportional contract rate or on a time-and-materials basis for incomplete work
All non-cancellable material orders, subcontractor commitments, and vendor deposits placed on Client’s behalf prior to the termination date
Reasonable demobilization costs and overhead incurred as a direct result of the termination

17.2 Termination for Cause

Either party may terminate a Project Agreement for material breach upon written notice if the breaching party fails to cure the breach within fifteen (15) days of written notice describing the breach in reasonable detail. Marenzo Construction Group may also suspend or terminate work in the event of Client’s non-payment beyond fifteen (15) days of the applicable due date.

17.3 Suspension of Work

Marenzo Construction Group reserves the right to suspend work without liability if: (a) Client fails to make timely payment; (b) Client’s actions or omissions create unsafe working conditions; (c) hazardous materials are discovered that have not been remediated; or (d) necessary permits, approvals, or site access have not been obtained. Work will resume upon resolution of the applicable condition and Marenzo Construction Group will not be liable for any schedule delays or cost impacts resulting from a justified suspension.

18. Lien Rights

Marenzo Construction Group expressly reserves all rights available under Wisconsin’s construction lien statutes (Wis. Stat. Ch. 779) and any applicable public project bond statutes. Nothing in these Terms constitutes a waiver of Marenzo Construction Group’s lien rights or any other rights available at law or in equity for non-payment.

Client is responsible for notifying Marenzo Construction Group of any lien waiver requirements applicable to the project at the time of contracting, including those imposed by a lender, landlord, or title company. Partial and final lien waivers will be provided by Marenzo Construction Group in exchange for corresponding payments actually received and cleared.

19. Safety

Marenzo Construction Group is responsible for maintaining a safe work environment for its employees and subcontractors on the project site, in compliance with applicable OSHA standards, Wisconsin Department of Safety and Professional Services (DSPS) regulations, and other applicable safety requirements.

Client, Client’s representatives, and Client’s Design Professional must coordinate all site visits with Marenzo Construction Group’s project superintendent in advance and must comply with all posted safety requirements and site access protocols while on the project site. Marenzo Construction Group reserves the right to restrict access or require escort of all visitors on active construction sites for safety and liability reasons.

20. Confidentiality

Each party agrees to hold in confidence any proprietary or non-public information received from the other party in connection with a project (“Confidential Information”) and not to disclose Confidential Information to third parties without the disclosing party’s prior written consent, except as required by applicable law, regulation, or court order.

This obligation does not apply to information that is or becomes publicly known through no fault of the receiving party, was independently developed by the receiving party, or was rightfully received from a third party without restriction.

21. Force Majeure

Marenzo Construction Group will not be liable for delays, cost increases, or failure to perform resulting from causes beyond its reasonable control, including acts of God, severe weather events, floods, fires, natural disasters, pandemics or public health emergencies, governmental actions or orders, supply chain disruptions, material or labor shortages, strikes, or other force majeure events. Marenzo Construction Group will notify Client in writing promptly upon becoming aware of a force majeure event and its anticipated impact on the project schedule and cost.

22. Governing Law

These Terms and any Project Agreement are governed by and construed in accordance with the laws of the State of Wisconsin and applicable federal law, without regard to conflict of law principles. The parties consent to the exclusive jurisdiction of the state and federal courts located in Milwaukee County, Wisconsin for any matter not subject to arbitration under Section 23.

23. Dispute Resolution

23.1 Good-Faith Negotiation

The parties agree to first attempt resolution of any dispute through good-faith negotiation. Either party may initiate this process by providing written notice describing the nature of the dispute and the relief sought. The parties will have thirty (30) days from such notice to attempt informal resolution before proceeding to mediation or arbitration.

23.2 Mediation

If the dispute is not resolved through negotiation, the parties agree to participate in non-binding mediation before a mutually agreed mediator in Milwaukee County, Wisconsin prior to commencing arbitration. The cost of mediation will be shared equally by the parties.

23.3 Binding Arbitration

If mediation does not resolve the dispute, the matter shall be submitted to binding arbitration in Milwaukee County, Wisconsin, administered in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association (AAA), or before a mutually agreed arbitrator. If the parties cannot agree on an arbitrator, either party may petition a court of competent jurisdiction in Milwaukee County, Wisconsin to appoint one. Judgment on any arbitration award may be entered in any court of competent jurisdiction.

23.4 Small Claims Carve-Out

Notwithstanding the foregoing, either party may bring a qualifying claim in small claims court in Milwaukee County, Wisconsin within that court’s applicable jurisdictional limits, without obligation to first negotiate, mediate, or arbitrate.

24. Modifications to These Terms

Marenzo Construction Group reserves the right to update these Terms at any time. Material changes will be communicated to active clients in writing or posted on our website with a revised “Last Updated” date. Continued engagement with Marenzo Construction Group following notice of updated Terms constitutes acceptance of the revised Terms. The Terms in effect at the time a Project Agreement is executed will govern that specific project.

25. Entire Agreement

These Terms, together with the applicable Project Agreement (including any executed change orders and attachments), constitute the entire agreement between the parties with respect to the subject matter hereof and supersede all prior and contemporaneous negotiations, representations, warranties, and understandings, whether written or oral. In the event of any conflict between these Terms and an executed Project Agreement, the terms of the Project Agreement govern.

If any provision of these Terms is found to be unenforceable or invalid under applicable law, that provision will be modified to the minimum extent necessary to make it enforceable, and the remaining provisions will continue in full force and effect.

26. Contact Information

For questions about these Terms, project inquiries, written notices, or contract matters, please contact:

Marenzo Construction Group

6055 North Flint Road, Unit #1

Milwaukee, WI 53209

Phone: (414) 540-1615

Email: accounting@marenzogroup.com

Website: https://marenzogroup.com/